Featured
INVITATION TO BIDDERS Sealed ...
INVITATION TO BIDDERS
Sealed proposals will be received by the Limestone County Board of Education, until 2:00 P.M., legally prevailing time, on March 10th, 2026, for the Limestone County School Football Turf Replacement, Group 1, Concessions and Restrooms at Limestone County Board of Education Board Room, 300 South Jefferson Street, Athens, Alabama, at which time and place they will be publicly opened.
A cashier's check or bid bond payable to Limestone County Board of Education in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000, must accompany the bidder's proposal. Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract.
Bid documents may be obtained from www.ward-scottplans.com, Electronic PDF copies of bid documents may be procured free of charge. Physical copies of Drawings and Specifications may be ordered and picked up at Datatek Reprographics, 2108 Island Cir, Huntsville, AL 35801.
Bid bonds are to be issued by an acceptable bonding company licensed to do business in the State, with a Power of Attorney, to confess judgment thereon, with the understanding that it shall guarantee that the bidder shall not withdraw his bid for the guarantee period of sixty (60) days after the scheduled closing time for the receipt of bids; that if his bid is accepted, he will enter into a formal contract with the Owner, and that in the event of a withdrawal of said bid within said period, or the failure to enter into said contract within the time specified, the bidder shall be liable to the Owner for the full amount of the bid guarantee as liquidated damages and not as a forfeit or as a penalty. The bid bond and certified checks on unsuccessful bidders will be returned upon awarding the contract or rejection of all bids, in no event, later than the number of days in the guarantee period from the opening of proposals. That of the successful bidder will be returned when formal contract and bonds are accepted and approved.
Bids must be submitted on proposal forms furnished by the Architect or copies thereof. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect; the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner's judgment, the best interests of the Owner will thereby be promoted.
All Bidders are invited to attend a mandatory pre-bid conference to be held at 1520 W. Elm Street, Athens, Alabama at 10:00 A.M. on February 26th, 2026. The bidder's company employee attending the pre-bid conference shall have qualifications and experience with the construction to be performed within this project. Any questions concerning the pre-bid conference shall be directed to the Architect.
Nonresident bidders must accompany any written bid documents with a written opinion of an attorney at law licensed to practice law in such nonresident bidder's state of domicile, as to the preferences, if any or none, granted by the law of that state to its own business entities whose principal places of business are in that state in the letting of any or all public contracts.
The News-Courier
February 18, 25, 2026
March 04, 2026
Sealed proposals will be received by the Limestone County Board of Education, until 2:00 P.M., legally prevailing time, on March 10th, 2026, for the Limestone County School Football Turf Replacement, Group 1, Concessions and Restrooms at Limestone County Board of Education Board Room, 300 South Jefferson Street, Athens, Alabama, at which time and place they will be publicly opened.
A cashier's check or bid bond payable to Limestone County Board of Education in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000, must accompany the bidder's proposal. Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract.
Bid documents may be obtained from www.ward-scottplans.com, Electronic PDF copies of bid documents may be procured free of charge. Physical copies of Drawings and Specifications may be ordered and picked up at Datatek Reprographics, 2108 Island Cir, Huntsville, AL 35801.
Bid bonds are to be issued by an acceptable bonding company licensed to do business in the State, with a Power of Attorney, to confess judgment thereon, with the understanding that it shall guarantee that the bidder shall not withdraw his bid for the guarantee period of sixty (60) days after the scheduled closing time for the receipt of bids; that if his bid is accepted, he will enter into a formal contract with the Owner, and that in the event of a withdrawal of said bid within said period, or the failure to enter into said contract within the time specified, the bidder shall be liable to the Owner for the full amount of the bid guarantee as liquidated damages and not as a forfeit or as a penalty. The bid bond and certified checks on unsuccessful bidders will be returned upon awarding the contract or rejection of all bids, in no event, later than the number of days in the guarantee period from the opening of proposals. That of the successful bidder will be returned when formal contract and bonds are accepted and approved.
Bids must be submitted on proposal forms furnished by the Architect or copies thereof. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect; the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner's judgment, the best interests of the Owner will thereby be promoted.
All Bidders are invited to attend a mandatory pre-bid conference to be held at 1520 W. Elm Street, Athens, Alabama at 10:00 A.M. on February 26th, 2026. The bidder's company employee attending the pre-bid conference shall have qualifications and experience with the construction to be performed within this project. Any questions concerning the pre-bid conference shall be directed to the Architect.
Nonresident bidders must accompany any written bid documents with a written opinion of an attorney at law licensed to practice law in such nonresident bidder's state of domicile, as to the preferences, if any or none, granted by the law of that state to its own business entities whose principal places of business are in that state in the letting of any or all public contracts.
The News-Courier
February 18, 25, 2026
March 04, 2026
Posted Online 6 weeks ago
Check back daily to see new goods and services, or to sell more stuff.
Place an Ad